FOR,Existing Entry
READ,"Delivery period of subject store is hereby regularized up to 30/06/2011 i.e. the last lot of subject store
was received on 30/06/2011, subject to conditions that no price/taxes/ED increased on any account
whatsoever which take place after original delivery date of the Acceptance of Tender will be allowed
and also subject to condition that recovery endorsed if any on inspection notes copies 2 and 5 will be
recovered by the paying authority.
perusal of the averments made in the following paragraphs of the petition :,
“1. That The Petitioner Union of India through its Competent Officer is partly aggrieved by the award dated 25.10.2018 received on 31.10.2018,
passed by Ld. Sole Arbitrator with respect to the dispute arising out of supply of 59000 jackets vide A/T dated 27.04.2010. The impugned award in so,
far grants Claim No.2 in favour of the Petitioner is legally unsustainable and apart from being violative of public policy of India is also in breach of the,
fundamental policy of Indian Law.,
2. That the brief facts leading to the filing of the present petition are as under:-,
xxx xxx xxx,
(ix) That the Ld. Arbitrator after having heard the parties rejected claim no.1 but allowed claim no. 2 in favour of the respondent which was pertaining,
to the imposition of liquidated damages. The Ld. Arbitrator directed the release of a sum of Rs.501,60,825/- which was withheld by the petitioner to",
release in favour of the respondent. It is this portion of the award-which is under challenge in the present petition.â€,
(The emphasis is mine),
15.1 Besides this, even the perusal of the grounds incorporated in the petition reveals that the challenge is made only qua the amount awarded in",
favour of the respondent by the learned arbitrator vis-a-vis claim No.2.,
16. That being said, somehow in the prayer clause, the petitioner seeks a direction for setting aside the impugned award with respect to claim Nos.2",
and 3.,
16.1 To my mind, this is an aberration as the relief does not correspond with the averments made in the petition. Therefore, my examination of the",
impugned award is confined to claim no.2. I may also add that even if I had taken a more indulgent view of the matter and allowed the petitioner to,
amend the petition, in my opinion, the petitioner could not have cured the defect as the period of limitation for filing of Section 34 petition has long",
expired.,
17. Be that as it may, in allowing Claim No.2, the learned arbitrator has adopted the following reason d‟etre:",
(i) The delay with regard to the performance of contract is attributable to the petitioner.,
(ii) The delay has been regularized by the petitioner via the communication dated 19.03.2014; an aspect which I have noticed hereinabove.,
(iii) No show cause notice was served on the respondent before imposition of liquidated damages.,
(iv) Even if the communication dated 01.04.2011 was treated as show cause notice, it was not adverted to in the petitioner’s communication dated",
26.06.2012.,
(v) The petitioner has failed to prove that it incurred any loss due to delay in supplies which had to be made by the respondent.,
(vi) Between the expiry of the initial tenure of the contract and the first extension, there was a hiatus and, therefore, the contract had died its “own",
death†on 28.12.2010.,
Submissions of the Counsel:,
18. Mr. Jaswinder Singh, learned counsel for the petitioner, has vociferously argued that the learned arbitrator has completely erred in observing that",
the contract died its own death after 28.12.2010 and that the contract was lifeless, so to say, between that date and 07.01.2011.",
19. It is submitted by Mr. Jaswinder Singh that the learned arbitrator failed to recognise the fact that when the second extension was granted on,
09.04.2011, it was made clear by the petitioner that the extension was subject to the right of the petitioner to levy liquidated damages.",
20. This apart, Mr. Jaswinder Singh contended that the petitioner was entitled to levy liquidated damages under Clause 19(e) of the contract at the",
rate of 2% of the contract value and that the learned arbitrator could have taken the amount so calculated as the minimum amount leviable as,
liquidated damages and based on the evidence made available to him, could have sustained the retention of money by the respondent upto ceiling",
arrived at in the manner indicated above.,
21. On the other hand, Mr. Vasisht, learned senior counsel says that there are several reasons as to why this court should affirm the award.",
21.1 First, that there is in fact no delay on account of the reason that the petitioner vide communication dated 09.04.2014 has regularized the delay, if",
any, caused by the respondent.",
21.2 Second, there is a finding of fact returned by the learned arbitrator that the delay, if at all, is attributable to the petitioner.",
21.3 Third, there is no averment in the Statement of Defence (in short “SODâ€) that the petitioner has suffered any loss and that loss could not be",
proved in the facts and circumstances of the case.,
21.4 Fourth, while exercising jurisdiction under Section 34 of the 1996 Act, this court cannot reappreciate the evidence.",
Reasons:,
22. I have heard learned counsel for the parties and perused the record. 22.1 According to me, the facts which I have stated above are not in dispute.",
There is no dispute that the petitioner had accorded two extensions. The first extension was granted on 08.01.2011 while the second extension was,
given on 09.04.2011. It is also not in dispute that while giving the second extension, the petitioner had reserved the right to levy liquidated damages.",
22.2 What has also come through, and qua which Mr. Jaswinder Singh has not raised any cavil, is that the respondent delivered the entire quantity of",
bullet proof jackets by 30.06.2011. The petitioner’s counsel has also accepted the fact, as noticed by me, that the supplies made by the respondent",
met the specifications stipulated by the petitioner.,
23. Therefore, all that this court is required to examine is as to whether or not, in the given facts, the petitioner was entitled to retain money towards",
liquidated damages. The learned arbitrator via the impugned award has concluded that the retention of money towards liquidated damages was not,
justified.,
24. As noted above, the learned arbitrator has based his conclusion on several limbs. While I am not in agreement with each and every limb of his",
reasoning, in substance, the following findings of fact cannot be interfered with by me while exercising jurisdiction under Section 34 of the 1996 Act.",
25.1 The first finding of fact returned by the learned arbitrator is that the delay is attributable to the petitioner.,
25.2 The second finding of fact, returned by the learned arbitrator, is that the petitioner regularized the period of delivery till 30.06.2011. Pertinently, in",
that letter, there is no caveat entered by the petitioner that it reserves its right to levy the liquidated damages.",
26. Given the fact that the respondent, admittedly, had made supplies by 30.06.2011, the petitioner, to my mind, thereafter could not have retained any",
money towards liquidated damages; assuming that it could be a judge in its own case qua which I have serious doubts.,
27. That being said, I am, in a sense, in agreement with Mr. Jaswinder Singh’s argument that the one limb of the reasoning is clearly suspect,",
which is, that the contract died its own death on 28.12.2010.",
27.1 Mr. Jaswinder Singh is right that if the contract was dead, then the extensions, based on which the supplies were made by the respondent could",
not have been regularized. In my opinion, this part of the reasoning contained in the award can be excised and the award, to my mind, can be",
sustained based on other findings of fact which are referred to hereinabove.,
28. In my opinion, the petitioner perhaps could have argued that it was not a case where damages can be quantified. The goods in issue were bullet",
proof jackets.,
28.1 However, the petitioner does not seem to have set up this case. There is no such averment in the SOD, at least none has been shown to me by",
learned counsel for the petitioner. There is no assertion in the pleadings by the petitioner that on account of delay in the supplies made by the,
respondent, it had suffered an injury and that injury had resulted in a loss. The petitioner, in my opinion, was required to make such an assertion and",
thereafter go on to plead that given the nature of the goods in issue, loss could not have been quantified. The principles of law as applicable to levy of",
liquidated damages has been reiterated several times over in various judgments. The earliest judgment in India is the Privy Council judgment in Bhai,
Panna Singh and others v. Bhai Arjun Singh and Ors., A.I.R. 1929 P.C. 179. The latest summation of the principles enunciated in earlier judgment is",
made in Kailash Nath Associates v. Delhi Development Authority & Anr., JT 2015 (1) SC 164. Besides this, I may also refer to a judgment of this",
court in Indian Oil Corporation v. Lloyds Steel Industries Ltd., 2007 SCC OnLine Del 116.9 Since on facts it is closer to the instant case, let me",
extract parts of the judgment to drive home the point.,
“The effect of the Indian Contract Act of 1872, sec. 74, is to disentitle the Plaintiffs to recover simplicitor the sum of Rs. 10,000, whether as",
penalty or liquidated damages. The Plaintiffs must prove the damages they have suffered. ...â€,
“55. It is clear from the above that Section 74 does not confer a special benefit upon any party, like the petitioner in this case. In a particular case",
where there is a clause of liquidated damages the Court will award to the party aggrieved only reasonable compensation which would not exceed an,
amount of liquidated damages stipulated in the contract. It would not, however, follow therefrom that even when no loss is suffered, the amount",
stipulated as liquidated damages is to be awarded. Such a clause would operate when loss is suffered but it may normally be difficult to estimate the,
damages and, therefore, the genesis of providing such a clause is that the damages are pre-estimated. Thus, discretion of the Court in the matter of",
reducing the amount of damages agreed upon is left unqualified by any specific limitation. The guiding principle is „reasonable compensation‟. In,
order to see what would be the reasonable compensation in a given case, the Court can adjudge the said compensation in that case. For this purpose,",
as held in Fateh Chand (supra) it is the duty of the Court to award compensation according to settled principles. Settled principles warrant not to,
award a compensation where no loss is suffered, as one cannot compensate a person who has not suffered any loss or damage. There may be cases",
where the actual loss or damage is incapable of proof; facts may be so complicated that it may be difficult for the party to prove actual extent of the,
loss or damage. Section 74 exempts him from such responsibility and enables him to claim compensation inspite of his failure to prove the actual extent,
of the loss or damage, provided the basic requirement for award of „compensation‟, viz. the fact that he has suffered some loss or damage is",
established. The proof of this basic requirement is not dispensed with by Section 74. That the party complaining of breach of contract and claiming,
compensation is entitled to succeed only on proof of „legal injury‟ having been suffered by him in the sense of some loss or damage having been,
sustained on account of such breach, is clear from Sections 73 and 74. Section 74 is only supplementary to Section 73, and it does not make any",
departure from the principle behind Section 73 in regard to this matter. Every case of compensation for breach of contract has to be dealt with on the,
basis of Section 73. The words in Section 74 „Whether or not actual damage or loss is proved to have been caused thereby‟ have been employed to,
underscore the departure deliberately made by Indian Legislature from the complicated principles of English Common Law, and also to emphasize that",
reasonable compensation can be granted even in a case where extent of actual loss or damage is incapable of proof or not proved. That is why,
Section 74 deliberately states that what is to be awarded is reasonable compensation. In a case when the party complaining of breach of the contract,
has not suffered legal injury in the sense of sustaining loss or damage, there is nothing to compensate him for; there is nothing to recompense, satisfy,",
or make amends. Therefore, he will not be entitled to compensation [see State of Kerala v. United Shippers and Dredgers Ltd., AIR 1982 Ker 281].",
Even in Fateh Chand (supra) the Apex Court observed in no uncertain terms that when the section says that an aggrieved party is entitled to,
compensation whether actual damage is proved to have been caused by the breach or not, it merely dispenses with the proof of „actual loss or",
damage‟. It does not justify the award of compensation whether a legal injury has resulted in consequence of the breach, because compensation is",
awarded to make good the loss or damage which naturally arose in the visual course of things, or which the parties knew when they made the",
contract, to be likely to result from the breach. If liquidated damages are awarded to the petitioner even when the petitioner has not suffered any loss,",
it would amount to „unjust enrichment‟, which cannot be countenanced and has to be eschewed.â€",
29. I may also indicate that since the instant action under Section 34 of the 1996 Act has been preferred after the amendment made to the 1996 Act,
via the Arbitration and Conciliation (Amendment) Act, 2015, the scope of the expression “patent illegality†has been substantially narrowed down.",
30. With the insertion of Subsection (2A) in Section 34, the award can be challenged, inter alia, on the ground of patent illegality appearing on the face",
of the award provided it does not relate to either erroneous application of law or reappreciation of evidence. Therefore, according to me, at the",
highest, all that the petitioner could contend was that there was an erroneous application of law which according to me is not wholly correct as there",
are facets in the award, to which I made a reference above, based on which the learned arbitrator’s ultimate conclusion can be sustained.",
31. Thus, for the foregoing reasons, I find no merit in the petition. The petition is accordingly dismissed.",
